52.227-10 Filing of Patent Applications--Classified Subject Matter.


As prescribed at 27.207-2, insert the following clause:
FILING OF PATENT APPLICATIONS--CLASSIFIED SUBJECT MATTER
(APR 1984)
(a) Before filing or causing to be filed a patent application in the United States disclosing any subject matter of this contract classified 'Secret' or higher, the Contractor shall, citing the 30-day provision below, transmit the proposed application to the Contracting Officer. The Government shall determine whether, for reasons of national security, the application should be placed under an order of secrecy, sealed in accordance with the provision of 35 U.S.C. 181-188, or the issuance of a patent otherwise delayed under pertinent United States statutes or regulations. The Contractor shall observe any instructions of the Contracting Officer regarding the manner of delivery of the patent application to the United States Patent Office, but the Contractor shall not be denied the right to file the application. If the Contracting Officer shall not have given any such instructions within 30 days from the date of mailing or other transmittal of the proposed application, the Contractor may file the application.
(b) Before filing a patent application in the United States disclosing any subject matter of this contract classified 'Confidential', the Contractor shall furnish to the Contracting Officer a copy of the application for Government determination whether, for reasons of national security, the application should be placed under an order of secrecy or the issuance of a patent should be otherwise delayed under pertinent United States statutes or regulations.
(c) Where the subject matter of this contract is classified for reasons of security, the Contractor shall not file, or cause to be filed, in any country other than in the United States as provided in paragraphs (a) and (b) of this clause, an application or registration for a patent containing any of the subject matter of this contract without first obtaining written approval of the Contracting Officer.
(d) When filing any patent application coming within the scope of this clause, the Contractor shall observe all applicable security regulations covering the transmission of classified subject matter and shall promptly furnish to the Contracting Officer the serial number, filing date, and name of the country of any such application. When transmitting the application to the United States Patent Office, the Contractor shall by separate letter identify by agency and number the contract or contracts that require security classification markings to be placed on the application.
(e) The Contractor agrees to include, and require the inclusion of, this clause in all subcontracts at any tier that cover or are likely to cover classified subject matter.
(End of clause)
(R 7 -104.6 1969 DEC)


This page is a part of the TSA FAR-Master Search Site.

Access to this site without a purchasing a subscription from TSA is strictly prohibited.

Please direct comments about this site to FAR-MASTER Internet - webmaster <farweb@tsagate.com>. © TSA Inc.

Home | Search | Table of Contents | Help | Contact Us

Copyright © 1998 TSA, Inc. All rights reserved.